Bid Number: B23-16
Bid Title: Put-In-Bay Road TR #260 Resurfacing
Category: Ottawa County
Status: Open

Description:

Sealed bids will be received by the Board of Ottawa County Commissioners at their offices in the Court House, 315 Madison Street, Port Clinton, Ohio 43452 until 11:45 A.M., local time, March 23, 2023 at which time bids will be opened for the PUT-IN-BAY ROAD TR #260 RESURFACING PROJECT.   

PROJECT DATES:   START DATE:    The award for this project is expected to be in July.  Work may not commence until after the award and all contract documents are complete.  Contractor shall check the proposal and notes for additional restrictions in relation to the start date of this project.   DATE OF COMPLETION.          May 17, 2024        
Publication Date/Time:
3/9/2023 9:30 AM
Publication Information:
Port Clinton News Herald
Closing Date/Time:
Open Until Contracted
Submittal Information:
Submit bids to the Ottawa County Commissioners Office, 315 Madison St, Port Clinton, OH
Bid Opening Information:
March 23, 2023 11:45 am
Contact Person:
Questions regarding this project should be submitted on the form in the bid package and emailed to the Engineer's Office at OttawaCoEng@co.ottawa.oh.us.
Download Available:
Yes - see Engineer's listing
Fee:
Free to download
Plan & Spec Available:
The bid package, plans, specifications and any additional documents related to this project are posted at the bottom of the Engineer's Project listing.
Business Hours:
8:00 am to 4:30 pm M-F
Fax Number:
(419) 734-6768
Plan Holders List:
The Ottawa County Engineer’s Office does not maintain plan holder lists for any project.
Related Documents:
23-018 PIB Road - Legal Notice OPWC with delay in award date
3-23-23 Bid Opening - PIB Road TR 260 Resurfacing

Return To Main Bid Postings Page